Contract Clauses In EPC Thermal Power Projects: A Case Study Of Hai Phong Thermal Power Project

Demand of electrical energy in the world is increasing very fast with the development of economic and population growth in the global. In Vietnam, there are 27 Thermal power plants (TPP). The overall project duration for developing a thermal power factory is normally take 2 to 3 years depending on the size of facilities to be built.

Developing the facilities for a thermal power field such as platform, Thermal power Companies (hereinafter referred as the Project Company) normally sign an EPC (Engineering, Procurement and Construction) contract with the EPC contractor. For this field of industry, there are not so many EPC Contractors in the Asian South East countries who can execute a full EPC project, therefore the EPC contractor is normally selected and awarded thru the international bidding tender. The major factors for executing an EPC project are the contract clauses which are normally stipulated too generally with unclearly understanding and interpreting when having disputes between the contractor and the project company. Therefore, studying the method to develop the effective clauses in the EPC contract is necessary to simplify and make involved parties to understand and interpret clearly during the contract negotiation prior to the EPC contract signing and commencement. The understandable and applicable contract clauses properly will help an EPC project to be executed smoothly and effectively.

In order to minimize the interfaces and risks between the separated contractor and the project company during executing an thermal project, the thermal power companies normally prefer to award and sign an EPC contract with the EPC contractor, however this project delivery method will take a lot of time to make clarification, explanation and get the mutually agreement on the contract clauses between the contractor and the project company. The following problems are normally involved with the EPC contract clauses:

i. Take time to make the clarification and finalization before contract signing;
ii. Wrong understanding and interpreting of stipulated clauses in the contract;
iii. Conflict between contractor and the project company during project execution.

An EPC contract is generally applied for developing the thermal power project, in case of problems or disputes happen during the project execution, then these problems and disputes shall be resolved in accordance with stipulated clauses in the signed contract. Mr. Bui Tien Dung made a study which focused on the following issues related to EPC contract:

i. To study EPC contract process and management from literature review;
ii. To study the contract clauses in EPC thermal power project;
iii. To study the implementations of the contract clauses and their performance with reference to project advantages and problems.

Conclusions

Results from this report discussed and focused on some clauses applied for an EPC contract for developing a thermal power project as well as other EPC contracts in the construction industry. These clauses are normally defined and given by the Project Company in order to protect the project objectives and the Project Company from any kind of risks may happen. However from contractor’s point of view, it will be very risky if the Contractor complies with all these clauses without any exception or amendment. Therefore, providing the effective clauses based on the project documents and the Project Company’s interest shall be addressed during the bidding preparation and negotiation.

In summary, the effective clauses are the terms and conditions stipulated in the contract which shall be defined based on the interest and “win-win solution” basis for both the Project Company and the EPC Contractor.

Conclusion for important clauses in the contract that clearly identify risk, roles and responsibilities of each party

As discussed above, the EPC contract is quite complicated in term of legal issue, therefore the Project Company and the EPC Contractor shall have enough experiences and knowledge about the nature of project facilities in order to avoid their faults and minimize the risks during contract performance.

The Owner wish to transfer all of the construction risks to the contractor and be certain of his commitment. Usually, the responsibility for the package is vested in a single contractor, and bid evaluation is straightforward. The contractor agrees to carry out the work for the amount of money stated in the contract regardless of its actual cost as long as there is no change or breach of the contract from the owner. This is quite common for schools, warehouses and similar works where the scope is relatively well defined and the work is straightforward.

In this project, a fixed price lump sum turnkey contract is identified as the most suitable contract strategy provided the project could be completed within the owner’s budget. The owner can utilise model forms for the contract based on other projects procured in this manner.

Conclusion for the EPC project performance and how the contract contribute to the performance

The contract clauses are the most important tool to manage the EPC project. Therefore, the involved parties (Project Company, EPC Contractor) shall understand and know how to apply this tool effectively to manage the project in term of costly, timely and quality to the performence.

The contract clauses will be only effective when these are defined and stipulated in accordance with the project specification, documents and nature of work to be performed. Finally, these clauses also are established and finalized according to the mutually agreement between the Project Company and EPC Contractor.

General Conclusion

In conclusion, the major clauses in the EPC contracts are not the same for all project, these also depend on each project scope of work, complexity, specification and documents, the project company’s requirement and expectation and mostly on the outcome of contract negotiation between the Project Company and the EPC Contractor. Therefore, the meaning and application of major clauses in the EPC contracts shall be different in term of the standard form contract i.e. FIDIC or other organizations as well as in each kind of industry i.e. construction, etc.

His thesis abstract is copied and posted.

Abstract

Nowadays, the EPC contract is very wide applied in energy industry (specially in thermal projects) in this Region for developing an energy field project, this EPC contract is as a “fast track” tool to reduce the project duration. In order to execute this kind of contract successfully in term of the benefit for all involved parties, it is necessary to focus on some key factors that shall be affected on the project during execution phase i.e... contract terms and conditions clauses. Therefore, understanding and interpreting the application of term and condition clauses clearly in EPC contract will help the project to be executed and monitored by using the proper manning level in accordance with project specification and the project will be achieved its goals without the minimized disputations and conflicts happening.

This study will also discuss on the advantages and disadvantages of EPC contract from both Contractor and Project Company’s point of view and how to manage the EPC contract in accordance with term and condition clauses stipulated in the signed contract documents; how to resolve problems by understanding the contract clauses. However, the improvement of some major clauses are still needed in order to specify and define clearly the duties and responsibilities as well as obligations of involved parties to minimize the conflicts, interfaces, risks and disputes that can be happened during the project execution phase.

Cash Flow Projection Management For Small – Medium Sized Vietnamese Contractors

Construction is a complicated business that faces ever-changing conditions. Those who are not prepared or capable of meeting these demands may ultimately fail. Cash is the most important of the construction company resources, because of failure of cash management more than inadequate management of other resources (Singh and Lakanathan, 1992; Navon, 1994b). That inadequate cash resources are a cause of failure would rarely be disputed. However, the conclusion that temporary shortages of working capital may lead to failure might be challenged. The shortage of working capital may be real, and the shortage temporary, but the shortage is predictable and normal.

Mrs. Pham Thi Ngoc Hien conducted a case study which primary objectives were to: (1) study the theory of project cash flow management in construction; (2) synthesize the project management issues related to cash flow projection; and (3) apply project cash flow management into a case.

Conclusions

 Theory of cash flow

- This study is useful and limited to small and medium- sized projects. In large project the number of variables should be large and complex and takes long-time duration, it needs the deeper research with the help of software computer and take into account of the time value of money analysis and inflation affects. However, in the large project that consists of many smaller subprojects, these financing solutions may help bring the requirements and paybacks which are used as information or inputs to large projects.

- Adequate cash flow management benefits not only in cost control and assists profit acquisition for contractors but also contribute to other management skills. Individual project net cash flows contribute to and from the organizational cash flow which directly relates to the financial health of the organization. The key aspect to cash flow is to understand the way project cash flows layer over each other to generate organizational cash flow. A secondary aspect is to understand that organizational cash flow is dependent on the individual project profiles. Manipulation of these layered profiles has the capacity to change the organizational. In turn it is the overall management of a portfolio of net cash flow which determines the success of the whole organization. The aim of cash flow projection is to maintain the positive or at least manageable cash flow. In cash flow projection, the management of the timing of payments most important to the effective management.

- Cash flow management helps the contractor in inspecting project financing issues , resource usage and can be a useful tool to prove with banks.

- Combining the cash flow management and earned value technique, a project can be, a project can track the real status of progress, detect any early cost deviation, suggest payment strategy and be a factor that affects the scheduling for the coming projects.

 Project management issues related to cash flow management

- Cash flow forecast should be made at all phases of the construction process. Cash flow can be contributed to tendering stage to decide the agreement of the contract payment terms and schedule, decide whether accept or reject the bid; to construction stage to determine capital have to be available at a time, track the real status of the project ,set out a financial plan to recover costs; and retainage management.

- In project scheduling problems resources-constrained issue is generally considered essential for contractors as a means; furthermore there is an involving of cash flow in project scheduling. Contractor thus can evaluate appropriate project schedules under associated constraints, and arrange activities and resources.

- A company level cash flow model must be based on cash flows of all the company’s individual projects. The use of cash flow management at company level or project level helps the company to be in active position in any financial related decisions.

 Applying project cash flow management theory into a case study

- In portfolio project cash flow contractor should avoid accept the schedule and payment that caused the cash outflow and inflow of projects at the same time. Although following an abundant cash inflow. This cause a load at a time and an abundant at other.

- Small to medium Vietnamese should consider cash management as rational and idiographic evaluation in integration with empirical evaluation rather than only empirical process which focused solely on the project margin.

- The contractor doesn’t need to have a large working capital to run the operation of projects, just managing well the cash flow.

Her thesis abstract is copied and posted.

Abstract

Cash is the most important of all business’s resources. Many construction companies fail not because of technique or skills but the insufficient cash flow management (Singh and Lakanathan, 1992; Navon, 1994b). In progress-payment contracts, the contractor is paid for the work performed based on progress reports made at specified intervals. The owner holds back a percentage of the payments until the project are completed. The insufficient of time and amount of money contractor receives from client and pay to their supports causes the financial problems. This study provides concepts and tools that can be applicable during the construction phase based on the planned earned value and the actual incurred cost on a project from a general contractor’s viewpoint as the cash flow projection’s role integration to project management. Combining the cash flow and earned value technique, a project can track the real status of progress, detect any early cost deviation, suggest payment strategy, adjusting the planned schedule and be a factor that affects the scheduling for the coming projects.

Keywords: Percentage, Payments, Project, Insufficient, Construction, Lakanathan, Schedule, Technique

Implementation Problems Causing Cost Overrun Of World Bank-Supported Construction Projects: A Case Study In Afghanistan

The World Bank's projects have very important role in achieving strategic goals of the Afghanistan National Development Strategy (ANDS) that is a five year development plan to carry out the country's development cycle further than the post-conflict situation. The present environment of the country that is the implementation domain of all development projects, is currently effected by number of difficulties such as lack of security, lack of complete governance, corruption, lack of adequate infrastructure, and poverty. Since, the solution process of these challenges may take longer time as it is indicated in the ANDS in URL1 (http://www.ands.gov.af), planning, and implementing development projects in such environment may be more difficult than implementing them in a stable field. The uncertainty of problems against successful implementation of projects makes the risk management processes more complicated; therefore, most of preventing assumptions become not applicable, or projects even face new and unpredicted circumstances. Dealing with these un-forecasted barriers, in order to run and to complete the projects, not only requires extra managerial challenges, but it often causes project delay, and further expenditures than the estimated budgets.

In brief, the on-time completing the World Bank-supported projects in Afghanistan within the approved budgets is difficult because of an uncertain environment and many aspects of problems. Most likely, every unexpected constraint, and implementation risks have to be compensated by accepting some additional expenditures, the amounts of which are often too large and significant. On the other hand, executive procedure of providing these additional funds may not be an easy process because of the Bank's policies, Government regulations, and deal of other concerning entities within the country. So, keeping the World Bank-supported projects in Afghanistan within their budgets or at least reducing their extra costs as much as possible, are considered a very important issue for PIUs and the government. In order to take effective decisions in this concern, first of all necessary to be identified particular problems in the area that directly or indirectly cause the projects' cost overrun; second need to be studied the nature of their causations, and finally have to be found out, and applied most suitable methods of controlling these problems.

Mr. Mohammad Sharif made a case study which primary objectives were: (1) identifying what are the significant problems that often cause the World Bank- supported projects‘ cost overrun in Afghanistan; (2) studying the reasons why these problems cause cost overrun; and (3) analyzing how to mitigate the cost overrun risks

Conclusions

1. Although within the uncertain post-conflict environment of the country, in which the construction projects are subject to be implemented different political, legal, organizational, and cultural challenges are likely to affect the sound implementation of the projects finally ending to their cost overruns, most of the identified problems either have been looking like managerial or financial types of problems, or at least arising from these two areas. It means that the project management teams have to study these issues in advance and have to set effective practical plans and strategies to deal with them. A summary of the related areas of the identified problems are given in the table below.



2. Analysis show that the main involving stakeholders of these projects along the implementation phases of the projects' life cycles were the general contractors, the related government departments, and the project implementation units as it was assumed in the conceptual framework below. The most of identified items through the objective one were related to these organizations. The consulting agencies that usually have important role in this interval can be considered either as a part of PIUs or as the general contracting units based on the related points of view. In this research those are reflected on as general contractors.


Accounting Model
(Source: http://systemizesoftware.com/databuilder.aspx)

Since the identified problems are strongly interrelated they can be linked to each other based on a hierarchy of causes and effects according to the logical framework approach of problem solving. After analyzing the case reports, and the related literatures there were found the most likely reasons for the sixteen identified problems as below:

1. The problem of lacking capable construction companies in area is due to:
- Poor technical and managerial skills of site managers and engineers; also, lack of sufficient plants, due to their poor financial capacities.
- Inadequate investigations of capacity issues in establishing a new construction company, and
- Lack of security that impacts the willingness of foreign companies to work in Afghanistan.

2. The main reasons of poor human resource capacities of Afghan construction companies are:
- Ineffective site monitoring by owner organizations
- Non realistic organizational structures of contracting companies
- Poor condition of infrastructure
- Unsafe environment of the country
- Instability of labor market
- Dependence of labor supply to particular agencies, and
- Unsafe working conditions and other de motivation factors

3. Poor financial management of contracting companies are due to:
- Missing preparation of financial plans
- Unavailability of Bank credits
- Unavailability of financial data, and
- Inadequate administration of contracts

4. Delay by contracting companies are cause because of:
- Late start, slow mobilization, late materials and components delivery
- Wrong arrangements with the related government agencies
- Job site accidents
- Missing financial commitments by the partners
- Cash flow limitations, and
- Default

5. Poor involvement of top management in site works is happened because of undertaking several projects by the contractors, or their own businesses

6. Poor contribution of government agencies in fulfilling their committed responsibilities is because of:
- Human resource issues
- Corruption
- Limited annual budgets. and
- Lack of common, and clear goals, strategies, or lack of strong commitments to it
- Bureaucratic administrative systems

7. Dual chains of command comes from:
- Inadequate leadership and ineffective approach of motivation
- Difference between the dynamic requirements of the projects, and the government, and
- Relevance of project to other sources

8. There are no adequate codes for engineering designs due to:
- Lack of a national standard or clear regulation requiring a specific system or code for engineering issues
- Less enforcement of the quality and standardization of construction, and
- Different systems of academic institutions outputs

9. Project risks are not assessed and managed, since there are:
- An extra uncertain environment, and an ongoing military and security challenges in the country
- Lack of detailed and clear risk assessment functions within the PIUs, and
- Partly involvements of project managers with the whole life cycle challenges of the projects due to their late assignments

10. Missing the hierarchy of project planning is the result of:

- Lacking realistic strategic plans in the benefiting organizations that reflect all required projects with its hierarchies and priorities
- Missing the existing strategic plans, and
- Supporting some particular and a specific intervals of the overall plans by some special random investments

11. Incompleteness of design documents are because of:
- Poor contribution of the projects' partners
- Fixed and limited budgets, and
- An ineffective coordination by the project management units

12. Inadequateness of bidding process are caused by:
- Lack of security, authority of warlords
- Corruption, and
- Lack of qualified contractors

13. Variations during the implementation phases are generated due to:
- Constructive changes
- Inadequate design
- Poor coordination arrangements by responsible groups, and
- Lack of security, or authority of warlords

14. Delay in fulfilling financial commitments is occurred because of:
- Incomplete documentation
- Inefficiency of some line departments, and
- Poor financial capacity and management of the committing parties

15. Authority of warlords in the site is due to:
- Lack of security and complete state governance, and
- Ineffective planning, and risk management

16. Inadequate weather can cause difficulties if there is either:
- Some unprecedented critical climate change, or
- The plans and schedules are not effective, and efficient.

3. Since most of the analyzed problems are interrelated through the cause and effect chains, the developed objectives also tend to be common in many cases. Consequently the proposed activities for achieving each objective even in cases of common objectives may be differed because of the natures of the original problems. It means that the various dimensions of the objectives will be supported by variety of activities subject to be performed by several agencies. The summary of the finally developed objectives that are listed in a hierarchical manner in terms of the commonness of the issue are as below:

1. Bringing the security to the country
2. Enforcement the law and regulations in entire aspects of project performance
3. Eliminating corruption from the public sector
4. Improving infrastructure development of the country
5. Full implementation of projects by Government agencies
6. Effective use of the assisted funds
7. Rebuilding the capacity of government agencies
8. Effective coordination with related agencies
9. Improvement of the quality of construction projects
10. Improvement of human resource capacity of Afghan construction companies
11. Improvement of financial viability of construction companies
12. Properly managing the implementation risks
13. Adequate planning & management of project resources
14. Enforcement of safety requirements in construction companies
15. Improving efficiency and effectiveness of monitoring systems

His thesis abstract is copied and posted.

Abstract

The World Bank-supported projects in Afghanistan that significantly contribute implementation of the country's national development strategy are often affected by cost overrun issues caused by a variety of problems in the current post-conflict environment of the state. The implementation phase; in which the several sub-components of the projects are executed in the area under direct responsibility of the government agencies, and technical consultancy of the project implementation units, are considered as a problematic stage of the projects' life cycle. A qualitative research based on case studies was designed to contribute the prevention of cost overrun problems of such projects through identifying the problem items; analyzing the causes; and proposing effective strategies for solving them. The methodology consists of determining research assumptions, data collection criteria, and developing interview forms through a literature review; preparing case reports; analyzing the cause and effect natures of the problems; converting the main causes to the objectives; and finally setting up the effective strategies for achieving them. The collected data encompassed different cost overrun cases of five construction projects in Balkh and Faryab provinces of Afghanistan under the two major "Strengthening the Higher Education" and" the National Solidarity" Programs supported by World Bank. Through the cross-case analyses were identified sixteen items concerned to the main three stakeholders such as the general contractors, the related government agencies, and the project implementation units. By structuring the cause and effect trees, there were listed out most likely causes of each problem, from which were developed the related long and short term strategies after converting them to the objectives. The long term strategies, some of which were already the parts of Afghanistan National Development Strategy were concerned to a numbers of the government agencies. Some non government agencies such as the Afghanistan Reconstruction and Development Services through which procurement of the projects are conducted, the Project Implementation Units, and the General Contracting Companies were assigned to make more detailed operational contributions in ongoing project management processes. The result of the study were a set of the identified problems causing cost overrun of the mentioned projects in Afghanistan, a comprehensive table showing the causes, the objectives and strategies of its solutions, and the contributing departments of each strategy; and separate allocation of issues to the four key stakeholders of the projects.

Assessing Project Management In Myanmar Construction Companies

Many organizations are project-based in their operations and process, therefore they had to plan, manage and complete the project more successfully. Such project-based operations put pressure on project manager to plan, integrate, control schedule and improve overall organizational performance. However many organizations are uncertain, complicated and misdirected about the current applications of project management. Consequently, many companies are having major problems in implementing or improving their project management processes. This is especially important to project managers who have responsibility for implementing project management processes and practices in their organization. To perform the project success, engineering and construction organizations need to have high maturity levels and capabilities in performing in project activities.

Myanmar is a developing country which infrastructure needs to develop from buildings, transportation, telecommunication and etc. Many companies are interested in construction business for sure profit, but most projects are not successful. Therefore, how to enhance the success of the projects has become the important task for Myanmar practitioners and researcher. These delays can be avoided or reduced by identifying the major causes of delay and implementing good project management.

The management of construction projects has faced many difficulties, so project management (PM) should be improved. Ms. Saw Sandar made a case study which main objectives were: (1) to study PM implementation and PM process in Myanmar Construction Company; (2) to investigate organizational maturity and project management maturity; (3) How organizational maturity and project management maturity affect the project performance; and (4) How organizational maturity affect the project management maturity

Results of the Study

The results are based on the SPSS analyses.

1. Project management process in Myanmar construction organizations

Most of the construction companies in Myanmar were small and medium enterprises and they were family types. Authority and power was distributed to the lowest level, so the organization structure was flat and communicate easily. In addition, top manager of Myanmar construction companies were spent enough time in running the projects and the quality control system. As a result the quality of construction project was good and they got acceptable client satisfaction.

For the project management, although Myanmar construction projects were created WBS by subdividing the major project deliverables, project managers were weak in looking for impacts to constraint of time and budget when change order occurred. For the procurement management, most project managers were not assured the timely flow of materials and they cannot minimize the procurement to reduce the purchase costs which were excess uses of resources. As a result, most of the construction projects were cost overrun and cannot deliver on time.

2. The dimension of organizational maturity and project management maturity

In this study, organizational maturity is the combination of project management knowledge, project management attitude and actual project practices. The organization will be mature when the organization has knowledge on input, process and output and an understanding of the whole picture. The maturity level of organization will increase if the organization has attitude of low uncertainty avoidance, low power distance, femininity and collectivism which is strongly cohesive force between the groups. In addition, the organizational maturity level will be increased when the actions at top management level, tactical level, admin level and operative level are well applied during the project operation.

Project management maturity is based on nine knowledge area that means project management maturity is the degree of project management best practices which are developed by implementing project integration management, project scope management, project time management, project cost management, project quality management, project human resource management, project communication management, project risk management and project procurement management.

3. Organizational Maturity, Project Management Maturity and Project Performance

The result of analysis showed that the organizational maturity and project management maturity is significantly positively correlated to project performance. Organizational maturity is the combination of project management knowledge, project management attitude and actual project practices. The results indicate that these factors are significantly positively correlated with project performance. That means that the mature the organization, the better the project performance.

The results showed the time criteria for project performance are not correlated with the dimension of organizational maturity of project management knowledge about input, process and output. However the mean score of project management knowledge about input, process and output are not too low, over 3.5 (acceptable). It can be concluded that most of the Myanmar construction companies have acceptable knowledge on how to acquire qualified construction materials and human resources requirements and good understanding in the effective way to operate the projects, the projects were still cost overrun and delay. This is due to external factors such as rising in construction costs, lack in updating technical performance, took long time to meet the government regulation and sometimes the projects were have to stop due to heavy rain and flooding. Therefore, in order to successfully operate the construction project, external factors must have to consider.

Project Performance

Based on the result of this study, it can be concluded that in order to finish the project on time, project scope management, project quality management and project procurement management should be given emphasis when running the project. The researcher found out that most of the Myanmar construction projects were weak in this project management and especially in procurement management. Most developer and construction contractors were suffering from lack of finance, since construction materials were imported and the prices varied all the time. Therefore they cannot manage the materials to reach the project sites on time.

4. Organizational maturity and Project management maturity

The result of analysis showed that the organizational maturity is significantly positively correlated with project management maturity. That means the higher the organizational maturity, the better the project management maturity. On the other hands organizational best practices influenced project management best practices and vice versa.

Organizational maturity assessment provides identifying and measuring the participants knowledge about project management, attitude towards project management and actual project practices of an organization. Furthermore, project management maturity assessment also provides measuring project management maturity by analyzing nine project management knowledge areas. This study analyzed the strength and weakness of project management practices of construction companies and it also identified the problems that the project managers face in the project management process. In addition, companies should benchmark their operation by using these assessment questionnaires which are logical references to make process improvement.
Her thesis abstract is copied and posted.
Abstract

The construction industry is vital for the development of any nation, even though construction projects are commonly faced in uncertainty due to low maturity of project management and the nature of the project. Construction industry is performance industry compare to another industry. To perform the project success, engineering and construction organizations need to have high maturity levels and capabilities in performing in project activities. This study was based on quantitative research through questionnaires and conducted to identify the organizational maturity, project management maturity and how it effect on project performance.

This study was conducted in Myanmar construction companies and construction projects to study organizational maturity and project management maturity. The overall organizational maturity means score for Myanmar construction industry is 3.66. The result found that project management knowledge, project management attitude and actual project practices of organization are prerequisite for organizational maturity. The best project management practices based on nine knowledge area and it can improve the project management maturity.

The result showed that the organizational maturity and project management maturity is significantly positively effect on project performance. That means the mature the organization and project management, the better the project performance. In addition the organizational maturity is also positively correlated with project management maturity. On the other hands, organizational best practices influences project management best practices. This study indicates not only correlation of organizational maturity, project management maturity and project performance but also the best practices for organization and project management

Owner’s Contract Administration For Project Time And Cost Control Strategy In Commercial Building Projects

The construction industry development in Vietnam suddenly improved when it becomes a member of World Trade Organization (WTO). Vietnam impressed foreign investors who come to find the opportunities to invest in construction market. In recent years, a number of the investment in commercial construction building has increasing. Majority of foreign investors invest with projects such as office building, commercial center, apartment and commercial center building, hotel, resort with commercial services etc. These projects have gaining a large amount of GDP bringing benefit for economic growth.

Commercial building projects are especially time sensitive. Due to high construction costs and tight deadlines, they require state-of-the-art analysis and design, innovative thinking, quick turnaround, and quality service. Owners and contractors must have a good contract which can contain activities such as change control and contract maintenance, cost monitoring and charges, payment procedures and ordering, management reporting. The critical of contract administration for the contract’s success, and for the provider and customer relationship, could not be underestimated.

Following Patil, causes of delay in completion of projects include:
• Failure to handover full possession of the site within a reasonable time from the date of commencement.
• Failure to supply full and complete set of working drawings, designs, decisions etc., at the commencement of the work or as and when necessary. In some projects the delay is on account of late approved by the engineer to the Engineer to the working drawings, where the same are required to be prepared by the contractor.
• Failure to supply materials and/or power agreed to be supplied by the employer to the contractors as and when needed or demanded.
• Failure to organize and get done the work to be executed by other agencies so as not to hinder the main contractor’s program.
• Failure to pay at proper time the mobilization advance, the running account bills, cost of extra items and also failure to release requisite exchange, etc.

Therefore, weakness of capacity from owner side in managing construction contract lead to project cost overrun compared with estimated cost. It might rise from the shortcoming of preparing of project inception such as:
• Poor project scope definition and control.
• Design changes from client.
• Inadequate preparing for bill of quantity (BoQ)
• Various construction contract types
• Change orders in construction phase

Mr. Nguyen Xuan Phong wanted to find out usual and specific problems which affect directly to contract management on all phase of the entire of project. He conducted a survey to client contract managers to identify successes and fail factors and how these factors affect to project cost and project cost control, then, giving the comment to help clients control the contract to minimize cost overrun in commercial building project. His study objectives were to: (1) investigate the contract administration which can be used by project client to manage commercial project in Vietnam; (2) investigate the existing practices of project client in Vietnam in managing contract; and (3) propose recommendations and develop a process of contract administration by using multi-case study method.

Conclusions

The results of this study are discussed in three main catalogues.

1. Investigate the Owner’s contract administration
Six projects are determined under the applying of multi-case analysis in qualitative methodology and they are gathered into two cases groups. Once, DB cases group reveals the trend of the investor in commercial building in Vietnam when choosing delivery method is employing fast-tracked method for time saving and sooner operate the constructed building. Once, current practices of DBB cases group emphases the weakness of project time scale. For instance, in the life cycle of tender phase it takes time if there were no bidder selected.

Almost cases reveal a usual attitude of the owner when choosing the out sources of contract administration which prove that the need of a contract administration process is highly emphasis. It is able to apply the process whether the owner have or have no in-house staffs of contract administration

2. Commons and specifics activities in existing practical
The existing practical are investigated in effort of attempting to find the commons activities and specific activities by examining the critical problems occurred during all the phases of project.

3. Process of contract administration
Common activities are collected by the selected answers in the papers of multi-choice questionnaire and including verbal interview. A development of construction process between DB and DBB delivery is summarized which will be the fundamental to develop a contract administration process for these kinds of project delivery. Table below contains the full activities for individual stage of project from concept to close-out. It distributes an improvement to the system control capability, reducing cost overrun and project delay, examining potential cost benefit saving.




Recommendation

In area of construction project, to prevent the project from cost overrun and delay and smoothly implement construction activities regarding continue phases within budget and scheduled time contract management engineer need to be aware of construction phases in detail and having their own requirement. Nevertheless, the phases of construction project should be adopted appropriate with contract administration progress. Thus, author develops a process of construction project, purpose a progress of contract administration for DB and DBB projects comprise with other forms of check-list that mentioned on the chapter 2 and on the discussed cases.

His thesis abstract is copied and posted.

Abstract

For construction project, contract is the most important to every project’s participation such as owner, constructor, vendor, and supplier. Therefore, the appropriate contract administration for contract management is vitally important to determine the practical of any construction project. In decade of construction industry, the traditional delivery known as design-bid-build and design-build delivery is widely using in commercial building projects. According to construction industry development, nature of construction project are increase in size and becoming more complex that led to number of shortcoming in management system. Thus, this study conducts to assist the project owner understanding and implementing contract administration in Vietnam.

The study conducts to analysis cases on implementing the design-bid-build and design-build of commercial building projects which are highly increasing on demand of trading services market, domestic and foreign investments in Vietnam by using multi-cases study methodology. The objectives are emphasized on how the owner’s organization interact with the efforts of contractor, implementation of contract administration process, critical problems and their responds during phases of construction project. Data were collected through personal interview from project manager department and contract management members; it included contract documents, relevant reports of these cases.

The study finding covers the lack of contract administration capability in the owner organization to manage the contract. The commons of existing practical are determined as well as problems occurred on practices with specific activities of contract administration of each case. Assisting the owner to overcome the worsening situation, it is recommended that a detailed process of contract administration should be developed that investigate the contract management of each project.

Key words: Construction Contract Administration, Design-Build, Design-Bid-Build, Construction Phases, Project Delivery, Project Owner.

Asset Management in Public and Public Private Partnership (PPP) Hydropower Stations in Nepal

The need of infrastructure assets is increasing day by day. People around the globe are facing the infrastructure deficit each day. Generally government focuses on the new development of the infrastructure without keeping view of management of the infrastructure assets. Negligence to maintain asset to its designed performance level well in time will cost huge investment later on to recover (Hudson et al., 1997). In the past, decisions on investment and maintenance of infrastructure were made as per the political considerations, personal experiences, intuition and resource availability. Instead of considering strategic asset management, controlling backlogs as a short term solution was a common practice to measure success in asset management (Too et al., 2006). The conventional approach of asset management focused much on operation and functionality while failed to prove infrastructure asset as an economic resource where investment could be financially feasible, and socially and environmentally sustainable.

Hydropower, an electricity generation from kinetic energy of water, is a type of infrastructure. Electricity generation in Nepal is inadequate, unreliable and expensive (Asian Development Bank, 2009). For the past five year, public hydropower stations are able to generate only 73% of the designed average annual generation. In the year 2009, NEA has suffered a loss of 4.68 billion with cumulative loss of 12.33 billion (NEA Annual Report, 2009). Furthermore, Nepalese people are suffering from load shedding ranging from 2 hours to 16 hours a day for years. A part of these consequences can be attributed to asset management of hydropower stations. In this connection, it is worthwhile to investigate the asset management in hydropower stations of Nepal.

The contribution of asset management towards the overall performance of the asset is very high. However, the asset management is seldom practiced in a structured approach. Mr. Raj Kumar Lakhe made a study which main objective was to compare asset management practices in public and PPP hydropower stations in Nepal applying the investigation criteria developed in this study. To achieve this main objective, these sub-objectives were required:
1. To explore hydropower asset management factors and then develop criteria to investigate asset management practices in hydropower stations in Nepal.

2. To investigate the existing asset management practices in public and PPP hydropower stations of Nepal and conduct comparative study on distinct features which can affect the operation and maintenance sustainability.

3. To propose and recommend for improving the asset management in hydropower stations in Nepal

Conclusions

Investigation Criteria for Asset Management of Hydropower Stations

The investigation criteria for the asset management practices in hydropower stations along with the identified factors are validated by face-to face interview with the professionals in this sector. The verified criteria under seven factors are: 1) Local people as stakeholder, issues from them and attempts to address those issues from the management 2)Organizational development in terms of capacity development, motivation and training to the plant staff 3)Inventory management system in keeping records of operation and maintenance and balance of the spare parts and tools 4) Generation with respect to annul average designed generation and major outages & breakdowns as key performance indicators at the station level 5) Maintenance approaches adopted by the management 6) Provision of project documents as well as maintaining asset database and 7) Existing conditions of structures and equipment assessment process of the hydropower stations. The criteria are applied in each of two public and PPP power stations in this study. The investigation criteria can be used to other hydropower stations to know the internal strengths and weakness of the power station in managing their hydropower assets for operation and maintenance sustainability.

Public and PPP Practices in Hydropower Asset Management

Hydropower stations in Nepal both public and PPP are weak in managing hydropower assets. The cross case synthesis implied that within public and PPP power stations, there are significant differences in asset management practices. The size of the project basically governs the structure of asset management, the larger the power station, the better the asset management practices. However, lower cost of financing, operation and maintenance cost within the estimated amount and maintaining minimum balance of spare parts are observed in public practices. PPP power stations have shown better structured asset management in terms of project implementation, stakeholder relationship, organizational development, maintaining asset database, monitoring asset condition and carrying preventive maintenance for high reliability. The research findings on distinct features in asset management of public and PPP hydropower projects are summarized in the figure 1 below.



The procurement guidelines set by the donors with specified consultant, contractors and equipment supply are the main causes for the high initial investment cost of public projects. The decision making process is highly bureaucratic and centralized in public sector that is why all issues from local people are dealt at corporate level. Lack of determination and sense of belongings are the results of frequent transfer of staff. Lack of core technical personnel is apparent everywhere in public stations. Less attention to maintenance of existing plants and annual maintenance budget based on history without any initiation in schedule maintenance have made breakdown maintenance as the rule of work. The end result is, huge investment required to bring back the plant in operation, forced outages and hence low plant utilization, low productivity and higher generation cost. The researcher finds difficulties associated with operations of intake gate, trash rack, and other civil and hydro mechanical parts are caused due to lack of attention which do not require the especial expertise in the field.

Different financing structure is practiced but a joint venture with the vendors, contractors and power purchaser is in common practice in PPP projects. A proper mix-up of national and international design and construction team either through competitive bidding or direct negotiations have helped to lower the initial project cost in the context of PPP projects. A direct negotiation with the vendors establishing long term relationship in operation and maintenance are also in practice. A partially decentralized system is there for the operation and maintenance team and most of local peoples’ demands are assessed and addressed by the station management. PPP power stations are effective in retaining staff by implementing motivation schemes and developing sense of belongings of the individual to the company. The structures are intact and schedule maintenance is the maintenance approach carried out incorporating the hydrological cycle of the plant so as to optimize the generation. Higher plant utilization and higher productivity is the end result of the structured asset management practice in the PPP hydropower stations in Nepal.
Recommendations for the Improvements

Instead of taking into account long term structured asset management, tactical asset management is a common practice and measuring the success in terms of overcoming backlogs are the main pitfalls in the asset management of public hydropower power stations. While PPP better know the investment in strategic asset management of hydropower station is financially feasible and economically viable. Following recommendations for the improvements with intended objectives in asset management practices of hydropower stations in Nepal are summarized in the Table 1.

His thesis abstract is copied and posted

Abstract

The hydropower organizations in Nepal are constantly striving to ascertain the value addition to its stakeholders. Traditional delivery system alone has not been able to fulfill and sustain hydropower development. To overcome this limitation, public private partnership (PPP) has been introduced as an innovative public policy tool for the need of dynamism in traditional delivery approach. Despite the abundant hydropower potential in the country, the electricity generation is inadequate, unreliable and expensive. A part of these consequences can be attributed to hydropower asset management. In this connection, this study attempts to investigate the existing asset management practices in public and PPP hydropower stations in Nepal.

Based on the verified investigation criteria, each of two public and PPP hydropower stations are investigated through direct interview with station managers and site observations. The results are analyzed using explanation building as the specific analytic approach in the case study. The distinct features of asset management in public and PPP practices are identified, analyzed and highlighted.

The research findings reflect that both public and PPP practices are weak in managing hydropower assets in Nepal. The cross case synthesis implies that within public and PPP power stations, there are significant differences in asset management practices. However reduced cost of financing, though initial investment is higher by 35% than in PPP, maintaining minimum balance of spare parts and lower operation and maintenance cost are identified in the public practices. While, PPP practices have revealed better structured asset management in terms of project implementation, stakeholder relationship, organizational development, maintaining asset database, monitoring asset condition and carrying preventive maintenance for high reliability which has resulted maximum plant utilization and higher productivity.

Cultural Dimensions Of Construction Engineers In Thailand Related To On-Site Management

Each individual have their own national culture which is inherent to their life when they live in their home country. Hofstede (1980) argued that people carry “mental programs” that are developed and reinforced through their experience, and these “mental programs” contain a component of national culture.

Cultural aspect in construction industry is also important. Hofstede (2005) stated that culture is more often a source of conflict than of synergy and cultural are a nuisance at best and often a disaster. People in management level know that culture has impact on their work but they do not think that culture can cause huge problems. However, many conflicts and problems are caused by national culture.

Construction industries are multidimensional and complex. It involves not only technical and financial aspect but also social aspect. All social behavior is related to culturally-based. Mishandling and mismanaging in culture different can cause risks. Construction company that would like to complete or manage construction projects must understand culture clearly (Pheng et.al, 2000). It is important for the engineer to understand about national culture that has effects on construction operation. It is necessary to understand national culture which may lead to conflict among organization and is related to project performance and achievement. The researcher tried to investigate the effect of cultural dimensions on behaviors, base on national culture dimensions, in construction organization in Thailand.

Mr. Adithep Roobleak made a study which objectives were to: (1) identify national cultural dimensions of the construction engineers; (20 investigate the practical behavior base on the cultural dimensions of the engineers at construction sites; and (3) propose appropriate recommendations to improve the behavior of construction engineers concerning effective management of construction sites.

Conclusions

The conclusions were brought out based on data analysis to corroborate the objectives of this study. The first objective was achieved by distributing questionnaire to identify culture dimension of the construction engineer. Mean calculating was used for test the culture dimension different between Thai people and the construction engineer. The second objective was done by interviewing the construction engineer and site observation. The researcher investigates behavior of the construction engineer affected by Hofstede cultural dimensions. The third objective was achieved after interview the construction engineer.

The culture dimensions on the construction engineer

Power distance overall score on the construction engineer is 2.62 (52.4 out of hundred). The score is not different from Thai national index (64.0) by statistical testing. The construction engineers tend to not accepting the feedback from their subordinate. They always give the order to their subordinates by using command and by passing the boss command is insubordination. However, the decision making for them should be done by group more than taking the boss decision. This means that the construction engineers keep distance between them and their subordinates. According to the survey, the construction engineers who have higher age tend to have more power distance also.

Uncertainty avoidance overall score on the construction engineers is 3.34 (66.8 out of hundred). The score is not different from Thai national index (65.0) by statistical testing. The construction engineers always go to observe work progress because they do not want to eliminate all the risk that may happen. They do not delegate that much work to their subordinates because they do not want to take responsibility after their subordinates fail. They using the new innovation for construction sometime only because they think that it may not work in their projects.

However, they do not give much punishment to their subordinates who fail to do the work because they want to keep their relationship. This can indicate that the construction engineers have a bit on high uncertainty avoidance.

Collectivism overall score on the construction engineers is 3.97 (79.4 out of hundred). The score is not different from Thai national index (80.0) by statistical testing. The construction engineers extremely want to work in team. They do not want to work individually and they prefer to get group training. They think that the reward should be given to everybody not to personally. They feel that group meeting is very important for them. This can point out that the construction engineers have high collectivism.

Masculinity overall score on the construction engineers is 1.54 (30.8 out of hundred). The score is not different from Thai national index (34.0) by statistical testing. The construction engineers are not emphasizing on project’s achievement rather than maintain relationship among others. It is more important for them to have better connection. They give same treatment to different gender in the project and they are not assertive leader. There are not large amounts of challenging work that they give to their subordinates. These indicators reveal the construction engineers to be more on femininity.

Long term orientation overall score on the construction engineers is 2.03 (40.6 out of hundred). The score is different from Thai national index (56.0) by statistical testing. The engineers have little commitment when they do the work and they do not want to stay with the company for long time. Actually Thai are long term oriented but most of the respondents are young so they believe that they can go for new company. The respondent company at that time was not in stable condition. This is the main reason that leads them to be short term oriented.

Recommendation to improve On-site management

For achieving the final objective of this study, the last research objective is completed by proposing the recommendation for improving on site culture management that appropriate Thai construction.

Employing the new construction is affected by high uncertainty avoidance. Working in group and taking group decision can reduce uncertainty avoidance in person. Thus, the company should set committee for taking decision about the new technique together. It is not only engineer from site operation who takes decision. High power distance also effect to using the new technique. Power distance can be reduced by having social activity between engineer and worker. Every construction site should arrange trips for everybody. This method reduces distance between engineer and worker.

Monitoring work progress is affected by high power distance. The workers do not want to tell real progress which is delay to engineers who has high distance between them. Thus, high power distance should be reduced. It can be reduced by having social activity like previous topic also. Uncertainty avoidance affects monitoring also. It has positive impact. The construction engineer has high uncertainty avoidance which makes them always check and monitor work progress.

Instructing can be affected by high power distance. Engineers who have high power distance give order by command. They do not persuade their worker. Even though some worker get use to with being told to do the work. It is still better to give orders by persuade the worker. The best way to motivate worker is giving their need according to Maslow theory. However, good relationship is also important. The construction engineers are feminism so they concern about relationship. This is positive factor for on-site construction management.

High power distance has negative impact to site safety. Thus, safety training should be done in group. The engineer and worker should be together in safety training. This makes reduction the distance between them. Collectivism is positive factor for safety because the engineer working together can identify more hazards. The worker also when working in group can communicate more about safety issues.

Feminism also takes positive impact for safety. Either engineer or worker who are feminism when face with unsafe behaviors or condition, they tend to stop working rather than continue the work. They do not concern only getting the job done. However, Feminism makes the engineers or workers do not report to safety officers about unsafe behaviors that their friend did during the work. It is because they do not want to lose relationship. It is common in Thailand for giving punishment or blame to the person who did unsafe behaviors. Thus, safety officer themselves should not look for the person who did it for giving punishment. They should find solution of it.

His thesis abstract is copied and posted.

ABSTRACT

Many studies have shown that national culture varies with different management practice, such as strategic decision making, leadership style and human resource management. The differences between management practices and national culture would affect performance at the workplace. This study tried to investigate the effect of different cultures dimensions, based on national culture dimensions, on behaviors of construction engineers in Thailand and tried to propose appropriate recommendations for effective management of construction sites.

The study used questionnaire as a research instrument. The questionnaire explores the national culture in each dimension of construction engineers. Interviewing and site observation was conducted to gain more understanding about the construction engineers. Data analysis is conducted by using explanation which all important evidences were describe and statistic methods were used to analyze data from questionnaire surveys.

The result from the study showed that every dimension of national cultures have an impact on the construction engineers. High power distance of the engineer mainly causes many negative impacts for managing construction projects. Uncertainty avoidance, Femininity and individualism also take both negative and positive impact to the projects. Long term orientations of the engineers are different from national score. The engineers are shore term oriented which cause them to have short term carrier and low commitment with company. The culture dimensions cause the engineer do things different from others who have different score in the culture dimensions. Those behaviors have an impact on site operation. Employing new technique, planning and monitoring, Instructing and site safety are affected by those behaviors. Thus, on site operation are effected by national culture. Adjusting the national culture dimension either increase or decrease lead to effective on-site management.